Terms of Trade
Before we shake hands please read our terms of trade.
1. Confidentiality and Copyright
This document and its attachments are provided in strict commercial confidence
Evidence Technology Holdings Pty Limited (Evidence Technology) If you are the
intended recipient of this document you must not disseminate, distribute or copy
it to anyone outside your registered organisation.
If you have obtained this document by mistake, please notify Evidence Technology
immediately by email at alert@evidencetechnology.com.
2. Standard Terms of Trade
2.1. Projects
When Evidence Technology agrees to perform work, it will do so either on a Fixed
Price or a Time and Materials basis. It may also agree to perform the work initially
on a Time and Materials basis and, when details of the work are defined and agreed,
and all unresolved issues have been resolved, to proceed on a Fixed Price basis.
2.2. Specification
A specification is always a physical document that has been prepared by either
the Client or Evidence Technology staff. It defines in detail what is included
in the work as well as what is excluded from the work. It places agreed
boundaries around both the scope of the work and the project required for
delivering the work. A specification is only ’agreed’ when it has
been physically signed by authorised officers from both organisations.
The specification will always state who is responsible for all
’materials’ costs (eg, equipment, special software licenses, meals,
travel and accommodation). Any change or variation to the agreed specification
must also be in writing and agreed by both parties in a similar manner.
2.3. Fixed Price Work
Evidence Technology will only agree to undertake work for a Fixed Price when
there is an agreed specification. In this case, the specification is binding on
both parties and the cost of performing any additional or previously unspecified
work (including all work that is not explicitly included in the specification)
will be charged to the Client. A Fixed Price project will almost always involve
progress payments being made by the Client. At the start of the project,
Evidence Technology will supply a Payment Schedule which will show the
deliverable milestone that each progress payment is tied to, the expected date
and the amount of the progress payment.
2.4. Changes and Variations to Fixed Price Work
Evidence Technology follows a standard industry practice for managing changes to
project scope. This process is documented and you are encouraged to familiarize
yourself with the process before engaging Evidence Technology in any fixed price
contract.
Where a change is introduced because of new or revised requirements or due to
assumptions being incorrect, Evidence Technology reserves the right to submit a
variation.
In all cases, irrespective of the nature of the change, an impact assessment
will be undertaken. The impact assessment will, at a minimum consider impacts on
cost and time or scheduled for any agreed fixed price work.
Unless otherwise agreed, the cost of undertaking impact assessment taking more
than 30 minutes will be passed on to the Client.
Unless otherwise agreed, Evidence Technology will assume include as part of any
assessment, impact on documentation, testing, user training, support and
maintenance.
2.5. Time and Materials Work
Performing work on a Time and Materials basis allows work to progress when there
is a large amount of uncertainty on projects. This is typically the case during
the early phases of a project when the system requirements are being defined.
Evidence Technology may agree to undertake work on Time and Materials basis and
may provide an estimated amount of effort to complete this work. These estimates
are not binding and are to be used for ’budgeting purposes’ only.
All hours actually spent will be charged. If, during the course of Time and
Materials work, Evidence Technology determines that the work will require
substantially more effort than estimated, Evidence Technology will advise the
Client who may then choose not to complete the work. In this case, all effort
spent on the work will be charged to the Client. The minimum time chargeable for
on-site work is two (2) hours.
2.6. Discounts for pre-paid or longer term engagements
Evidence Technology will apply discounts to its standard terms of trade in
return for longer term contractual commitments or for pre-paid blocks of time.
Discounts are negotiated on the time of application and will be applied after an
exchange of letter regarding terms of pre-payment or longer term engagements.
2.7.Hardware Procurement
Unless otherwise agreed, all hardware and equipment valued at more than $25,000
AUD (being the total value of equipment to be commissioned), Evidence Technology
will require an upfront payment of not less that 40% of the total agreed sale price.
It is the responsibility of the Client to provide formal orders for all equipment and
hardware at the time of purchase. An ‘advance invoice’ will be raised
against the order for the upfront payment. Normal settlement terms for an advance
invoice is 7 - 14 days. Evidence Technology will confirm the order and delivery/commissioning
schedules after receipt of formal confirmation of the Clients order and payment has been
made in accordance with the agreed quotation.
Please see the ‘managing exchange rate risk’ section below where
Evidence Technology is importing hardware components.
2.8. 'Turnkey' Managed Services
In certain situations, Evidence Technology may be prepared to offer Clients
'Turnkey' solutions that incorporate a package of equipment,
software and professional services. The Evidence Technology Managed Services
offering is specifically designed to enable Clients to avoid unnecessary
technology risk exposure via a 'partnership' model whereby each
party concentrates on its core business and respective competencies.
Under a managed service model, responsibility for day to day operation of the
solution, its underlying technologies and business processes that could
otherwise be performed by the Client is provided by Evidence Technology on a fee
for service basis. Typically, a Support Level Agreement (SLA) will be defined to
ensure that service availability is maintained at a level appropriate to the
Client's business requirements.
Evidence Technology charges a fixed monthly fee for the managed service over an
agreed contract term. An up-front component may be applicable depending on the
set-up costs and agreed structure of the service engagement. Evidence Technology
may require (where the Client chooses outright purchase of the solution for
Evidence Technology to manage) support and maintenance plans (refer below) to
form part of the managed service offering.
The Evidence Technology Solution and its components may either be transferred to
the Client at the end of an agreed term or Evidence Technology may agree to
retain ownership and responsibility for perpetual upgrades of the solution
including technology refresh to maintain a standard of service appropriate to
the Clients Business.
2.9. Expenses
Unless explicitly included as a component of a Fixed Price quotation, all
travel, accommodation and other out -of-pocket expenses incurred by Evidence
Technology in performing the work will added to the Client's account.
Travel and sundry costs associated with the provision of the services will be
charged to the client at cost plus 10% (excluding GST).
2.10. Schedules
Evidence Technology will meet all agreed scheduled milestones provided that the
Client:
1. Assigns knowledgeable staff to work with Evidence Technology on the project.
2. Client staff will be given sufficient time to respond to Evidence Technology
questions in a timely manner.
3. Client staff will meet with Evidence Technology team members on an on-going
basis to:
a. Refine solution requirements
b. Review and accept each of the project deliverables
c. Review project progress
And no act of force majeure occurs.
2.11. Training
Training will be included only where the Client has requested it. If the Client
requires additional training, it will be charged in half day or full day
sessions. Documentation, if required, is at additional cost. If documentation
has not been specifically estimated or quoted, it will not be supplied. All
documentation development and reproduction costs (including additions, deletions
and revisions) are to the Client's account.
2.12 Confidential Information
Evidence Technology's staff treat all information from Clients as being
’Commercial-in-Confidence’. Confidential Information of any nature
that either party discloses to the other party regarding any aspect of their
business shall be defined clearly in writing prior to it being made known to the
other party. Once Confidential Information is disclosed it will be treated in
strict confidence. Information so obtained shall not be divulged, furnished or
made accessible to third parties without the prior written permission of the
original party.
2.13. Intellectual Property and Transfer of Rights
If required, a separate agreement may be negotiated for the express purpose of
protecting the intellectual property of either party. In this case, all costs
associated with negotiating these undertakings will be passed on to the party
whose interest is being served. In the case of negotiations taking two (2) or
more hours, this will include Evidence Technology's time charged at
standard fee rates. Any title or rights of the subject services or product shall
not transfer to the other party until all associated fees and payments have been
made in full and in accordance with these terms of trade. In the case of
incremental, partial or milestone based releases of services and/or product, the
other party shall take custody of the service or product for the purpose of
review, testing and evaluating and retain them as the fiduciary agent of
Evidence Technology. No part or portion of any agreed rights or title are
transferred until agreed works have been completed, paid for in full and a
transfer deed has been executed.
2.14. Acceptance
Acceptance of services and/or the solution provided by Evidence Technology on a
Fixed Price basis will be based on the most recent version of the agreed
specification. In the absence of a specification or specific acceptance
criteria, payment made against a milestone achievement-based invoice will
constitute acceptance of the work performed covered by that invoice. The Client
may choose to perform acceptance testing against an agreed acceptance test plan
incorporating acceptance criteria, at its own cost. It is the Clients
responsibility to perform sufficient testing of the solution prior to and during
the warranty period so as to identify defects with the solution, the services
supplied by Evidence Technology and all of the deliverables produced by Evidence
Technology. Where service or product is delivered in part or in full and no
formal acceptance, testing or feedback is given by Client to Evidence Technology
within 14 working days of delivery, then they are deemed to have been accepted
in full. Any service or product used in a live environment prior to any formal
Client acceptance testing is deemed to have been accepted.
2.15. System Software Licensing
Unless explicitly included as a component of a Fixed Price quotation, the
provision of all system software will be charged to the Client's account.
System software includes operating system software, database management system
software, system administration software, backup software, anti-virus software,
internet browser software, office productivity tools (eg, Microsoft Word, Excel,
PowerPoint, Project and Access), etc.
2.16. Defects
A defect is defined as any situation where the solution or its supporting
documentation does not conform to the latest, agreed specification.
2.17. Warranty
Evidence Technology will provide a thirty (30) day warranty on all Fixed Price
work. This warranty period commences upon acceptance, or when the solution is
used in a live environment, whichever is the earlier (i.e., if the Client
chooses to ’go live’ with the solution before an acceptance test has
been performed or completed, then the solution will be deemed to have been
accepted and the warranty period will commence at the ’go live’
date). The planned start date for the warranty period will be communicated to
the Client well in advance of it starting, usually as an activity on the project
schedule. An extended warranty period can be provided if the Client wishes.
No warranty applies to work performed on a Time and Materials basis.
Evidence Technology and its suppliers disclaim all other warranties, either
express or implied, including, but not limited to implied warranties or
merchantability and fitness for a particular purpose, with regard to the
solution, the accompanying written materials and any accompanying hardware.
Evidence Technology pass on to the client any manufacturer’s published
warranty in full. At its own discretion, Evidence Technology may offer an
extension to this warranty. For example, the greater of 25% of the manufacturer
’s standard warranty or 6 months. Warranty extensions are only applicable
for equipment that is covered by an Evidence Technology support service plan.
For example, where Evidence Technology (or an approved partner) is engaged to
provide a managed service (hire, rent, lease or operate) or where Evidence
Technology is engaged to provide preventative maintenance support services
covering specific equipment items.
Warranty means ’free defect repairs’. Warranty does not include any
support. During the warranty period, if Evidence Technology is requested to
perform any work that is not in the nature of repairing a defect or included as
part of the agreed specification, then the time spent performing this work will
be charged to the Client's account. In the special circumstance where a
defect is found that masks significant other (downstream) defects and is found
during the warranty period, Evidence Technology may be prepared to restart the
warranty ’clock’. Each defect is treated on a case -by-case basis.
Where there are multiple solution releases, there will only be a single warranty
period for the final solution release. Defects found during any usage of any
release of the solution other than the final solution release, will be repaired
by Evidence Technology during the development of the next solution release and
delivered in that next solution release.
2.18. Support
’Support’ means:
1. ’First Level Support’ (which itself means the provision of
HelpDesk services and liaising directly with solution end-users) AND
2. ’Second Level Support’ (which itself means the provision of a
support service to the providers of the ’First Level Support’) AND
3. ’Third Level Support’ (which itself means the provision of a
support service to the providers of the ’Second Level Support’).
First Level Support is usually provided by the Clients HelpDesk (but may be
performed by Evidence Technology if the Client so wishes).
Second Level Support is usually performed by the Clients Solution Support Group
(but may be performed by Evidence Technology if the Client so wishes).
Third Level Support is usually performed by Evidence Technology (but may be
performed by the Client if the Client so wishes).
Support includes responding to all service calls for the following:
1. ’How to’ questions
2. Notify problem
3. Notify defect
4. Request for password reset
5. Request for access to a full solution
6. Request for access to solution functionality/software menu items
7. Request for change to solution functionality
8. Initial and on-going business staff training
9. Initial and on-going technical staff training.
Any work performed by Evidence Technology over and above these items (including,
but not limited to, assisting with Client-related business or IT issues,
assisting the Client with installing and supporting their IT infrastructure,
business consulting or work outside the agreed specification) will be performed
on a Time and Materials basis. Service calls are to be made to Evidence
Technology either via the Evidence Technology HelpDesk telephone number, an
e-mail to the Evidence Technology HelpDesk or by using the Evidence Technology
Service Management System).
Support does NOT include:
1. On-site visits
2. Hardware support
3. System software support.
2.19. Maintenance
’Maintenance’ means:
1. ’Defect Repairs’ AND
2. ’Solution Enhancements’ (which itself means the provision of
small amounts of software development services).
First Level Maintenance is usually performed by the Clients Information Systems
Support Group (but may be performed by Evidence Technology if the Client so
wishes)
Second Level Maintenance is usually performed by Evidence Technology (but may be
performed by the Client if the Client so wishes). Where a defect is reported to
Evidence Technology in any solution or service Supplied by Evidence Technology,
steps will be taken to rectify the defect as soon as possible. Evidence
Technology will provide either defect correction information (eg, a
’patch’), a work-around or other remedial services as may be
necessary to restore the solution or service to a standard as described in the
latest, agreed specification. Defects can occur and be repaired in the following
scenarios:
1. While the solution is under development (including during acceptance testing)
2. During the warranty period
3. After the warranty period has ended
Where a defect is found while the solution is under development, it will be
fixed by Evidence Technology at no additional cost to the Client. Where a defect
is found during the warranty period, it will be repaired by Evidence Technology
at no additional cost to the Client if the project was performed on a Fixed
Price basis. If the project was on a Time and Materials basis, the cost will be
to the Clients account. The repair may be supplied after the warranty period has
ended. Where a defect is found after the warranty period has ended, it will be
fixed by Evidence Technology on either a Pre-Paid basis or a Per Call basis.
Evidence Technology will charge its standard time and materials rate to correct
any defects resulting from any of the events outlined below:
1. Operation of the solution in a manner which is inconsistent with the intent
of the solution as described in the most recent version of the agreed
specification.
2. Operation of the solution in ways other than those described in the most
recent version of the agreed specification.
3. Use of the solution in an information technology environment other than that
specified in the most recent version of the agreed specification.
4. Failure by the Client to use the solution in conformity with the most recent
version of the agreed specification and/or in any supporting instructional
material that has been delivered by Evidence Technology.
5. Failure of any information technology equipment or system software.
6. Any other service specifically excluded or where the specification is unclear
or open to misinterpretation.
Solution enhancements are considered to be those that each requires less than
ten (10) person days of development. Maintenance does NOT include large scale
solution enhancements and development.
2.20. Support and Maintenance
Solutions will be supported and maintained by Evidence Technology either under a
Pre-Paid basis or on a Per Service Call basis. Clients operating on a Pre-Paid
basis are guaranteed a faster response to problems as well as guaranteed that
Evidence Technology will always have someone who is trained in your solution.
Clients operating on a Per Service Call basis will be charged a Time and
Materials based-fee based on the amount of time spend on the service call. The
minimum service call duration is billed as fifteen (15) minutes. Support and
Maintenance normally commences on the same date as the warranty period
commences.
Evidence Technology recommends that all Clients purchase Support and Maintenance
with their Evidence Technology products. Standard Support and Maintenance is
calculated at twenty two per cent (22%) of total cost of commissioning per annum
of the RRP of the Evidence Technology products and is payable quarterly in
advance. It offers all upgrades and patches to the software for the duration of
the maintenance agreement along with phone and email support.
Software Maintenance only is available at 15% of the total RRP of the software
and provides all upgrades and patches to the software for the duration of the
agreement. Support and Maintenance is only available when a Evidence Technology
trained engineer or qualified (Evidence Technology Authorised) technician
installs the software.
2.21. Client's Obligations
It is the Clients obligation to:
1. Operate the delivered solution according to the instructions given by
Evidence Technology.
2. Create and maintain an operating environment that can be used to run the
solution.
3. Administer the operating environment in a professional manner (including, but
not limited to, performing backups, monitoring solution logs, tuning the
solution for improved performance, maintaining solution user access security,
provision of a disaster recovery environment that allows the solution to operate
should the main environment become non-operational).
4. Notifying Evidence Technology of any suspected defects in a timely manner.
5. Make timely and clear decisions and provide instructions to avoid delays and
interruptions that may impact on Evidence Technology, its ability to fulfil its
service obligation to the Client and the costs it incurs to deliver agreed
product or service.
6. You must:
a. Comply with all laws and guidelines concerning your use of the Services
b. Notify us immediately of any change to your details, and
c. Contact Evidence Technology immediately if there is a problem with the
Services.
2.22. Account Management Planning
From time to time Evidence Technology initiated account management support
activities including special meetings, networking activities or social
engagements. These will be identified in advance as 'non chargeable
activities'. The objective of account management activities is to build a
mutual understanding on Evidence Technology and Clients business objectives or
address any issues reated to the engagement model.
In general, account management time will not exceed 2 hours per month.
2.23. Assessing our Performance
Periodically, Evidence Technology may request that the Sponsor of the agreed
works provide it with a 'Client Satisfaction Score'. This is a
simple subjective measure from 0 = very unsatisfied to 10 = very satisfied. The
purposed of this approach is to track our performance over time. Where
performance is considered to be 'below expectation' then Evidence
Technology will request a review meeting and specific information as to what it
needs to do to achieve and exceed the expectations of the Project Sponsor.
If required, Evidence Technology would be pleased to provide a rating of its
satisfaction with the Client and its team.
2.24. Delays
The Client is responsible for ensuring that clear and timely decisions are made
so as to avoid Evidence Technology incurring costs associated with interruption
and delay. These costs include waiting time, cost and expense of temporarily
redeploying Evidence Technology personnel or contract staff, penalties and fines
for late delivery or conducting works outside or normal operating hours.
Where Evidence Technology has agreed to deliver product or services on a Fixed
Price or Managed Service Basis and delays arise as a result of events considered
outside of Evidence Technology direct control and within the control of the
Clients (ie. not a force majeure event) then Evidence Technology will charge the
Client, and the Client will not refuse to pay, all reasonable costs associated
with the delay. These costs may include the redeployment of resources which are
otherwise committed to works that have been delayed.
Evidence Technology applies fees and charges as outlined in Schedule A to
calculate cost of Client initiated interruptions or delays after having served a
notice that a delay or interruption will or has occurred which are out of
Evidence Technology control.
2.25. Exchange Rates
The Client is responsible for ensuring that orders are placed in a timely manner
such that Evidence Technology is not unnecessarily exposed to adverse exchange
rate fluctuation. From time to time Evidence Technology will provide quotes and
estimates for imported goods and services. Evidence Technology manages its
exchange rate risk via obtaining matching quotations from its suppliers and
equipment manufacturers.
Where orders are placed after the quotation term (normally between 14-30 days),
Evidence Technology reserves the right to vary the price of quoted goods to reflect
the additional cost of adverse exchange rate movements.
Where orders are placed within a quotation term (normally between 14-30 days),
then Evidence Technology will absorb the cost of small (up to 5%) exchange rate
movement but reserves the right to pass on additional costs to the Client (cost
increases above 5%). In either case, where exchange rate movements are favorable
(leading to more competitive prices), Evidence Technology will pass on the benefit
(where it exceeds 5% of the original quoted price) directly to the Client.
Any price revision is to be treated as a formal variation to the original quotation or
estimate (refer changes and variations)
2.26. Service of Notices
It shall be sufficient to serve all notices by facsimile, standard, certified or
registered post as well as any form of electronic mail to the other party's last
known address.
2.27. Disputes
Any disagreement, dispute or other action relating to the adequacy of the
services or solutions provided by Evidence Technology or either partys
compliance with the conditions of this agreement will be:
1. First, discussed in person at the time the matter becomes apparent.
2. Be declared in writing making specific reference to relevant parts of prior
jointly signed agreements, undertakings and/or the most recent version of the
agreed specification and any acceptance criteria.
3. Then a fourteen (14) day notice period be given to the other party to resolve
the matter as described above.
4. If the matter is unable to be resolved then an independent mediator (as
agreed by both parties or appointed by an appropriate registered mediation
authority) to facilitate resolution of the matter with costs being shared
equally by both parties.
5. And failing this be adjudicated exclusively by a court of competent
jurisdiction in Sydney, New South Wales, Australia.
2.28. Term and Termination
If the Client does not give Evidence Technology at least thirty (30) days notice
to end the contract, Evidence Technology will extend the Term on a month
by-month basis. Evidence Technology requires thirty (30) days written notice to
end the extended contract. The contract may be terminated by the Client if
Evidence Technology breaches the terms and conditions of the Contract and fails
to remedy the breach within thirty (30) days of being asked to do so. The
contract may be terminated under amicable terms by giving Evidence Technology at
a minimum of two (2) months written notice prior to the termination date. If two
(2) months notice is not given, Evidence Technology reserves the right to
invoice for the agreed block of Hours that would have been billed over the two
(2) months. Evidence Technology can permanently end the contract if the Client
breaches any term or condition of the contract involving the payment of money
and fails to remedy the breach within thirty (30) days of being asked to do so.
Evidence Technology will permanently end the contract by notice to the Client,
(without prior written consent) if Evidence Technology is legally obliged to do
so upon request from a government agency. If the Service ends as a result of the
Clients decision to terminate the contract, or as a result of a breach of these
Terms and Conditions:
1. Evidence Technology's rights, in respect of the Client's
unfulfilled obligations, under the contract at that time, continue
2. All hardware, software and any associated intellectual properties referred to
in section 2.9 required to deliver the Services remains the property of Evidence
Technology.
3. The Client must pay to Evidence Technology:
a. All costs and expenses incurred in ending the contract
b. All outstanding accounts at that time
c. The Exit Fees (unless the client terminates the contract because Evidence
Technology breaches the terms and conditions or the Term expires)
2.29. Suspension of the Services
Evidence Technology may temporarily suspend the contract if the Client breaches
any term or condition of the contract involving the payment of money and the
Client fails to remedy the breach within fourteen (14) days of being asked to do
so. Evidence Technology may immediately suspend the contract by notice to the
Client if Evidence Technology is legally obliged to do so upon request from a
government agency.
2.30. Assignment of Contract
Either party's rights under this agreement may only be assigned, after
prior written notice and acceptance by the other party to a subsidiary or
related body corporate. Such acceptance is not to be unreasonably withheld.
Assigning these rights transfers all rights and obligations as agreed under this
contract.
2.31. Miscellaneous
Any person signing the contract or any specification on the Client's
behalf warrants that they have full power and authority to the Client in respect
of the contract or specification. If any part of the contract is found to be
invalid or of no force or effect, it shall be construed as though such part had
not been inserted and the remainder shall retain its full force and effect. This
contract is governed by and construed in accordance with the law of New South
Wales, Australia.
2.32. Cancellations
If any Time and Materials work is cancelled after approval to precede has been
received, Evidence Technology will charge the Client for all effort and
out-of-pocket expenses incurred up to the time at which it was cancelled. If any
Fixed Price work is cancelled after approval to proceed has been received, then
Evidence Technology will charge the Client a proportion of the quoted Fixed
Price based on the effort and out-of-pocket expenses incurred up to the time at
which it was cancelled.
Where Evidence Technology agrees to accept upfront payments for the convenience
of the Client, Evidence Technology will credit the Clients account (ie. no cash
return) for the value of works incomplete where works have been halted or
cancelled at the request of the Client. In this case, Evidence Technology
reserve the right to charge the Client all reasonable costs associated with the
redeployment of resources which are otherwise committed to works that are halted
or cancelled by the Client.
2.33. Credit Terms
Unless otherwise agreed, credit terms are strictly fourteen (14) days. Evidence
Technology reserves the right to discontinue work where credit terms are not met
as well as take legal action for any outstanding debt. During the Term, the
Client agrees to pay the amounts specified in Schedule A ’Fees and
Charges’.
1. Evidence Technology will send an invoice in an approved form for GST purposes
setting out the Fees due for the Services provided.
2. The Client will pay the Fees regardless of whether it is the Client or the
Client's Clients who use the Service.
3. The Client will be solely responsible to pay or reimburse Evidence Technology
for the full amount shown in the invoice.
4. The Client will pay all invoices by the Due Date or, if the Client elects, to
pay by direct debit, Evidence Technology will debit the nominated account for
the amount of the invoice by the Due Date.
If the Client does not pay an invoice by the Due Date the Client agrees that:
1. Evidence Technology may charge a daily interest from the Due Date until the
date on which payment is received. Interest will be capitalized monthly and will
be payable at the rate which is two percent (2%) per annum above the overdraft
reference rate quoted by Evidence Technology's principal bankers on the
first day of the applicable month.
2. The Client will be liable for all reasonable collection costs (including any
legal fees) Evidence Technology may incur to collect the amount outstanding.
If the Client, in good faith, disputes an amount in an invoice, the Client must
notify Evidence Technology in writing within fourteen (14) days setting out
reasons for the dispute and the amount in dispute.
2.34. Solicitation of Staff
Solicitation of either party's employees or contractors by the other party
is prohibited. Both the Client and Evidence Technology warrants that should they
solicit an employee or contractor from the other party, thereby breaching this
prohibition, they will pay liquidated damages to the other party of a minimum
amount of one hundred and fifty percent (150%) of the annual salary (including
all commissions, bonuses and benefits) expected to be paid to the employee in
the new position.
2.35. General Liability
In no event shall Evidence Technology or its suppliers be liable for any
accidental, consequential, incidental or indirect damages of any kind (including
without limitation, damages for loss of business profits, business interruption,
loss of business information or other pecuniary loss) arising out of the use or
of the inability to use the solution. In no event shall Evidence
Technology's liability for any claims whether in contract, tort or other
theory of liability exceed the purchase price of the products, services or work
contracted, unless such limitation of liability is otherwise prohibited by law.
2.36. Limitation on Warranties
This is a services engagement. Evidence Technology warrants that it will perform
services hereunder with due care and skill in a professional manner.
To the extent permitted by law, the express warranties in this agreement shall
be in lieu of, and Evidence Technology excludes all, other representations,
conditions and /or warranties, express or implied, including any warranties in
respect of the services which might otherwise be implied by international
convention, statute or general law into this agreement.
Nothing in this Agreement will operate so as to exclude, restrict or modify
Evidence Technology's liability for any breach of any warranty,
representation, condition or any term implied by the Trade Practices Act 1974 or
any relevant state or territory legislation. Where Evidence Technology is liable
for a breach of any warranty or condition implied by the Trade Practices Act,
1974 (or equivalent warranties and conditions in state or territory legislation)
in respect of Services or Deliverables, Evidence Technology's liability is
limited (where permitted by the applicable legislation) to: (i) in the case of
services, the cost of having the services supplied again; and (ii) in the case
of goods, the lowest of the costs of replacing the goods, acquiring the
equivalent goods or having the goods repaired, whichever Evidence Technology in
its absolute discretion elects.
2.37. Limitation on Damages
To the full extent permitted by law, in no event shall either party nor their
respective employees, officers and directors be liable for any loss of profits,
lost management time, savings, contracts, revenue, invest, goodwill, data, or
penalties, fines or for consequential, special, indirect, or exemplary damages,
costs, expenses, or losses. To the full extent permitted by law the Client
agrees that Evidence Technology, its employees, officers and directors shall not
be liable to the Client for any actions, damages, claims, liabilities, costs
expenses, or losses in any way arising out of or relating to the services
performed hereunder for an aggregate amount in excess of the fees paid by the
Client to Evidence Technology in performing the Services. No terms of this
Agreement shall benefit or create any right or cause of action in or on behalf
of any person or entity other than the Client and Evidence Technology.
Evidence Technology's liability in contract, tort, negligence, strict
liability or by statute or otherwise under or in connection with this Agreement
will be reduced to the extent, if any, to which the Client contributed to the
loss or damage suffered as if apportionment of damages in the case of
contributory negligence applied to a claim based on a breach of contractual or
other duty. The Client must use best endeavours to mitigate all loss.
The provisions of this Section shall apply regardless of the form of action,
damage, claim, liability, cost, expense, or loss, whether in contract, statute,
tort (including, without limitation, negligence), or otherwise, and even if such
actions, damages, claims, liabilities, costs, expenses or losses has been
previously notified by the Client to Evidence Technology, and even where such
actions, damages, claims, liabilities, expenses or losses are caused by the
negligence of Evidence Technology, its servants, agents or contractors.
2.38. Force Majeure
Neither party shall be required to perform any term, covenant, or condition of
this Agreement so long as such performance is delayed or prevented by force
majeure, which shall mean any acts of God, wars, governmental laws, orders,
requirements or actions, enemy or hostile governmental actions, strikes,
lockouts, labour or employment difficulties, civil commotions, fires, floods,
accidents or breakdowns, or any other casualties or conditions which are beyond
the reasonable control of either party and not due to the fault or negligence of
such party. If, as a result of any of these conditions, either party fails to
perform any obligations specified in this Agreement and gives written notice of
the same to the other party within ten (10) days of their occurrence, then such
failure shall not be deemed a breach or default; and the applicable time periods
in which to perform shall be extended, but only to the extent and for the period
such condition exists. This provision shall not apply to any obligation to pay
monies.
Revision History
| Ver | Date | Drafting | Author |
| 1.3 | 01-10-09 | Extended warranty option added | PHC |
| 1.2 | 01-09-09 | General Review | JAW |
| 1.1 | 30-09-08 | Revision - Procurement & Exchange Rate Risks | PHC |
| 1.0 | 01-07-09 | Board Approved Published Terms | JAW/PHC |
| 0.9 | 01-07-08 | Review Draft | JAW/PHC |